If the Contractor fails to provide acceptable policies of insurance, the Owner may obtain such insurance at the cost and the expense of the Contractor. (2)original copies on the above date and year. Contractors Fee. Drafting. $1,000,000 combined single limit per occurrence. 40. Hiring a lawyer on ContractsCounsel is easy, transparent and affordable. manner affect the Work. and to, including the right to manufacture, use, reproduce, distribute by sale, rental lease or lending or by other transfer of ownership, to perform publicly, and to display, all such Developments, whether or not such items constitute all Contractor agrees and does hereby assign, grant, transfer and convey to the Owner, its successors and assigns, the Contractors entire right, title, interest and ownership in and to such Developments, including all intellectual property rights Contractors means and methods in performing the Work, the rights to and ownership of which shall solely reside with and belong to Contractor. If the parties representatives are not able to promptly settle the dispute, the senior executives of the Progress payments shall reflect the actual Cost of Work and the allocable portion of Contractors Fee for said period, but Contractor shall endeavor to perform the Work and bill in accordance construction of any provision of this Agreement, to rescind this Agreement, or to enforce or collect any judgment or decree of any court or any award obtained during arbitration, the prevailing party shall be entitled to recover its costs and Such consolidated mediation and arbitration otherwise shall be governed by the terms of this Section40. Trade discounts, rebates, refunds and amounts received The Owner shall pay the Contractor for the Contractors performance of its obligations under this Agreement the Cost of the Work (as defined in Section5) plus the The Owner may cancel this Agreement at any time and for any reason, without cause and for its convenience, upon written notice to the Contractor. for supervising, coordinating and performing all of the work. this Section20.1. 24. There are other documents that may need to accompany this agreement such as an operations manual or project specifications document which detail more specifics about how the work will be performed. payments not made, (5)the amount of such damages, and (6)all costs reasonably necessary to cure any failure to carry out the Work in accordance with this Agreement. 5.10 Premiums for insurance, to the extent of the portion A court agreement would drop the number of signatures needed to force a recall election. excess of 1.50 inches of precipitation for 2 or more consecutive days, and/or precipitation in excess of 2.00 inches of precipitation for 1 or more consecutive days, and/or precipitation in excess of 1.00 inches for 3 or more consecutive days, as Non-disclosure agreements (NDAs) are amongst the most common agreements that come across an in-house attorney's desk. The Owner may purchase and maintain, in a company or companies lawfully authorized to conduct business in the state where the Project is located, property insurance upon the entire Work at the site. time required for and directly related to the performance of the Work. copyrightable and whether reduced to practice, (ii)all patents and patent rights, copyrights, trade secrets, trademarks, and other similar property rights, and (iii)all Project process or operational writings, records, journals, 37.1.1 Termination for Bankruptcy Events. canceled or allowed to expire until at least thirty (30)days prior written notice to the Owner. A memorandum of agreement, or MOA, is a legal document describing a business partnership between two parties that have agreed to cooperate to meet an agreed objective or complete a project. No: Status of person: Name: . Contractor shall continue the Work and maintain the Schedule of the Work during any dispute resolution proceedings. Notwithstanding any provision of this Agreement and to the extent permitted by law, neither the Owner nor the Contractor, nor any of each of their subsidiaries, affiliates, directors, officers, employees or agents, be liable to the other party for completed except as agreed in writing in advance by the Contractor. Both parts are guided by the architect`s instructions at each step. Without to the Contractor. 1. brought by or on behalf of its employees or agents. 8.2 The Owner may withhold all or a portion of a progress payment or final payment on account of (1)incomplete Work, (2)defective or conceived, reduced to practice, developed, discovered, invented or made by the Contractor or Subcontractors during the term of this Agreement, whether solely or jointly with others, and whether or not while engaged in performing the Work. the Contractor shall perform the higher quality and the greater quantity of the Work except as directed in advance of the Work in writing by the Owner to do otherwise. 14. 31. changes, which shall be subject to arbitration if demanded by the Contractor. Contractor shall be responsible for all the acts and omissions of Subcontractors and their employees and agents. The decision of the arbitrators shall be final and judgment upon the award may be entered into any court having jurisdiction thereof. after the Contractor obtains knowledge of the event alleged to have given rise to the claim. 9.6 The Owner and Contractor agree that if Mechanical Completion for the Work occurs prior to the Guaranteed Mechanical Completion Date, the Owner shall Section20. In so doing, the Owner The name of the Corporation, the objects for which it is established and . Cancellation for Convenience. than fifteen (15)days after receipt of Contractors application for a progress payment. I have had my own law practice since 2014 and I enjoy solving my clients problems. Construction agreements are typically put in place between a contractor and the owner of a property. state where the Project is located which have a policy-holders rating of not less than A in the most recent edition of Bests Rating Guide. In the event of any remaining conflicts or inconsistencies between or among the Contract Documents, The The Contractor warrants that, property interest in such documents, shall not provide the documents or copies thereof to any third parties for any purpose except as necessary or required to perform the Work, and shall not use the documents on any other project or for any work P0000XXXX Revised: September 2012 ARTICLE 4 - PROGRESS PAYMENTS: The Owner shall make payments on account of the contract as provided in Articles 28, 29, 30 and 31 of the Standard General Conditions (1/98). Provided they remain in the employ of or otherwise affiliated with the Contractor, the persons referenced in this Section shall not be replaced Exclusivity. Spending on public construction projects fell 0.6% after slipping 0.2% in December. Accordingly, the Owner and the Contractor agree that in the event the Contractor fails to achieve Mechanical Completion by the applicable Guaranteed Mechanical Completion Date, the Contractor shall pay to the Owner as liquidated damages to with the Preliminary Schedule of Values attached as Exhibit B. Site Access. forty (40)hour work week and not utilize overtime or premium time rates or incur material or equipment expediting costs, unless the Owner has approved the use of such overtime or premium time or expediting costs in writing in advance. Cost of the Work shall, except to the extent reasonably allocable to the Work or the Project, exclude the following: 6.1 Wages, salaries 10.2 If the Owner and Contractor are unable to agree on the changes in the Contractors Fee or the changes in the Contract Times, the Owner may Standard Articles of the Owner-Designer Agreement - 2022-02-28. Contractor shall, as mitigation of the damages suffered by the Owner, at Contractors own cost and expense (including the cost of labor and equipment) promptly repair or replace with materials of new and good quality any Work or Cost for items incorporated into the Project, and the Contractor hereby assigns to the Owner all of the Contractors rights under such warranties. such Force Majeure Event or its direct or indirect effects, and thereafter require Contractor to resume full or partial performance of the Work in accordance with the provisions of this Agreement. names to appear on the insurance policies. This contract shifts all of the risks associated with a project and all of the benefits of unanticipated changes in material costs, labor costs and all of the risks and benefits of the . Final payment shall be made upon Mechanical Completion of the Work, subject to the provisions of Section8.2. All remaining costs shall be at rates comparable to the standard paid at the place of the Project . (the Owner Indemnified Parties) from, for and against any and all claims, demands, losses, costs, damages, expenses, penalties, actions, suits and liabilities, including without limitation investigation costs, attorneys and expert Any extra or changed work performed without prior written direction or approval of Owner shall not be compensated by Owner. 40.2.2 In addition to I have extensive experience in providing legal services and support in areas of business, labor & employment, IP enforcement (patent infringement, copyright & trademark), and other litigation matters; Reviewing, drafting, and editing business and legal documents/contracts; Conducting legal research and analysis, drafting memorandums, pleadings, discovery, document review, various motions, mediation briefs, and other litigation related activities; Reviewing and preparation of templates, policies, and processes for compliance with laws and regulations; educating and advising on legal and compliance issues. It can be used for projects such as building houses, office buildings, or other large-scale development projects. final payment, as set out in this Section8. The Cost of the Work shall be limited to costs reasonably incurred by the Contractor in the proper performance of the Work the parties shall submit the dispute to arbitration in accordance with Section40.2. expenses, penalties, actions, suits and liabilities, including without limitation investigation costs, attorneys and expert witnesses fees and other legal expenses, arising out of or related to this Agreement or the Work, including This section should clearly stipulate the names of parties involves, the project, location, and project start and end dates. Payment. Jonathan is the Founder and Managing Attorney of Liberty Legal Solutions, LLC, a law firm dedicated to building, protecting, and defending the business and personal interests of our clients in Oklahoma. 40.2.1 Arbitration proceedings and any trial court suit or The Contractor shall collect and submit to the Owner, upon Mechanical Completion of the Work, all warranties from Subcontractors supplying materials, equipment or components The parties shall request arbitration by a panel of three Contractor shall allow reasonable access to Contractors offices and other sites where the documentation is kept, and Contractor trial or arbitration, upon any motion for reconsideration, upon any appeal or petition for review, and upon any collection efforts or proceedings. Banks often require the use of AIA contracts and forms on projects they are financing. with the Owners own forces or by separate contracts. The The parties expressly agree that this Agreement was jointly drafted, and that both had opportunity to negotiate its terms and to obtain the assistance of counsel in reviewing its terms prior to execution. Period). Step 1: Describe the purpose of the contract in the title and preamble. for the Project so as to distinguish such material from material in preparation for other facilities or projects. 5.2 Wages of construction workers directly employed by the occurs first. owed to all Subcontractors. These costs include items such as utilities, telecommunications, water coolers, portable toilets, etc. 5.12 Costs relating to any general conditions and overhead reasonably allocable to the Work and not to any other project. tit. A121-2018, Standard Form of Master Agreement Between Owner and Contractor where Work is provided under multiple Work Orders is sometimes referred to as an "MSA," or the Master Service Agreement in the construction industry.In a general sense, the A121 is used by a single owner who expects to execute repeat projects with the same contractor. other documentation as the Owner or its lender or engineer reasonably shall require, shall be submitted to the Owner no later than the fifth (5th)day of each month, and the Owner shall make payment via wire transfer to the Contractor no later The MOU is an outline of your expectations, whereas a contract is a list of obligations. From renovations and reconstruction, to new project scopes, this article highlights five huge projects to keep an eye on this year. Hi there. five (5)calendar days after receiving notice of the request and (ii)Contractor to file an appropriate action within the bankruptcy court to seek assumption or rejection of the Agreement within ten (10)calendar days of the Blanket Contractual, Personal Injury, Products and Completed Operations, Broad Form Property Damage (including Completed Operations) and coverage for explosion, collapse, and underground hazards, with limits of liability of not less than the materials which fail to comply with the warranty during the Warranty Period. 20. The Renco Wall, Floor and Roofing System is a unique MCFR Building System that creates interlocking, fiber reinforced . This type of contract protects both parties by outlining each party's responsibilities in detail so there are no misunderstandings about obligations on either side. 9.3 The Contractor shall achieve Mechanical Completion (as hereinafter defined) of the Work not later Download ARTICLES OF AGREEMENT - Construction Labour Relations PDF for free. of the Work, except to the extent the defective or nonconforming Work is caused by the fault of negligence referenced in Section6.6. Payment Obligations. of the Owner, changes ordered in the Work or an event of Force Majeure (as defined in Section38), the Contract Times shall be extended by the number of calendar days that the Work as a whole is delayed pursuant to this Section13. 22.2 Any work performed by Owner agrees to cooperate with the Contractor and to require its separate contractors to do the same, with respect to scheduling, material and equipment deliveries and storage, security, cleanup, work activities and other aspects of the Project. Thats why I constantly stay on top of the latest developments in the law and business of startups, entertainment, art, intellectual property, and commercial enterprise. Without limiting the effect of the prior sentence, all portions or components of the Work designed by registered architects or skilled workers or enough proper materials or equipment, fails to make prompt payment to Subcontractors or for labor, materials or equipment, violates or disregards laws, statutes, codes, ordinances, rules, regulations or orders of any public this Agreement at any time be in conflict with any law, statute, rule, regulation, order or ruling and thus be unenforceable, or be unenforceable for any other reason, then the remaining provisions of this Agreement shall remain in full force and Fort Lauderdale Construction Agreement Lawyers, Los Angeles Construction Agreement Lawyers, Oklahoma City Construction Agreement Lawyers, Philadelphia Construction Agreement Lawyers, Salt Lake City Construction Agreement Lawyers, San Antonio Construction Agreement Lawyers, San Francisco Construction Agreement Lawyers. financier as collateral security (and in connection therewith, Contractor shall execute and deliver to the lender or financier a consent agreement in a form reasonably requested by such lender or financier) or (ii)to an affiliated or The Good Friday Agreement dictates that both the largest unionist and the largest republican parties must nominate the first minister and deputy first minister roles for the administration to . One of the unique features of an arbitration agreement is that it is treated as distinct and separable from the substantive agreement of the parties (even when it is nothing more than a clause in a long and complex contract): unless otherwise agreed by the parties, it is not regarded as invalid, non-existent or ineffective simply because the Aesthetics. The Owners election to take over all or any part of the Work shall not constitute the Owners sole remedy upon any such default. all or any portion of the Work, including any equipment or other item of Work which is lost, damaged or destroyed due to Contractors negligence, prior Business Contract Lawyers: How Can They Help. professional services are required of the Contractor, the Owner shall indicate all performance and design criteria to be satisfied. To the fullest extent permitted by law, Owner shall defend, hold Agreement or as soon thereafter as reasonably possible, the Owner shall provide the Contractor with evidence of financing in a mutually agreeable form, which shall include a deposit of the Contract Price, including any bonus potentially payable to In the event of such stoppage or suspension, the Contractor shall be entitled to an extension in the Contract Times equal to the length of the delay (the length of the stoppage or suspension plus the seven (7)or fewer days after Contractor will agree to perform contracting services relating to biodiesel and glycerin exclusively for Owner so long as tit. directly related to the Project process or operation or process-related research or investigations or results that are from or are suggested by the Contractors or Subcontractors performance of the Work, and (b)that are created, Form of The Owners approval shall not unreasonably be denied. 30. delay performance of the Work, reasonable action that Contractor could lawfully and reasonably initiate to remove or relieve either the Force Majeure Event or its direct or indirect effects has been identified and recommended to Contractor, and Waiver. 37.2 19. Cost of the Work performed up to the effective date of the termination (Contractors Fee at termination = (Contractors Fee) x (Cost of the Work performed up to the effective date of termination / Sum of Payments in Exhibit B, as presented in accordance with all requirements of this paragraph shall be deemed waived and forever discharged. and regulations. In lieu of actual delay damages, the Owner and Contractor agree that if Mechanical Completion is not achieved by the applicable Guaranteed Mechanical Completion Date, the amount of the Owners actual damages will be difficult to determine. Can a new employer ask for my last pay stub? (as further described below, the Cost of the Work), which shall exclude any components supplied by Owner or others. convenience, the Owner shall pay the Contractor the reasonable Cost of the Work plus the Contractors Fee, in an amount equal to the Cost of the Work performed up to the effective date of termination multiplied by the proportion of the Cost of direct the Contractor in writing to perform the changed Work and the Contractor shall immediately perform such Work. Unless otherwise agreed in writing, the warranty. In the construction industry, contractors utilize the services of subcontractors on a regular basis to assist with numerous tasks and specialty jobs. The Owner shall not occupy or utilize the Work until it is mechanically The Contractor shall promptly correct, at no cost to the Owner, all Work reasonably rejected by the Owner and all Work rejected by such agency representatives. Any suspension of performance and Change Orders shall be of no greater scope and of Contract Documents. Cruise on Real Pr. maintain one (1)record set of such documents; all other sets and copies of such documents shall be returned to the Owner upon Mechanical Completion of the Work. A contract is legally enforceable, but the MOU, just like an agreement, isn't. However, some parts of an MOU can be enforced. construction liens arising out of the Work. 42 Modification; Entire Agreement. audit of Contractors records, books and all other cost documentation at any time during or after the Project. I am a U.S. lawyer (licensed in California) and have recently relocated to London. If you are a contractor, it is a good idea to negotiate a heads of agreement with the principal before you enter into a final contract. The Contractor shall have no rights in the proceeds of such materials, unless they exceed the Owners costs of completing the UAW announcement of the tentative agreement at Caterpillar A worker in Decatur, Illinois, said, "The people I'm in a group text with are pissed. Download chapter PDF Author information. The Madison County Fiscal Court unanimously approved an interlocal agreement with the Richmond City Commission to create a men's rehabilitation center with the opioid settlement funds both . negotiation and arbitration as required herein, the Owner and Contractor agree to a single consolidated negotiation or, if necessary, arbitration of disputes between and among the Owner; Contractor; all Subcontractors and suppliers; architect, Section23: (a)the term hazardous materials shall mean and include all hazardous substances as defined in the federal Comprehensive Environmental Response Compensation Liability Act (CERCLA), all hazardous Contractor is directed to employ a 5. wage escalation provisions that may increase wage rates and, accordingly, the costs of labor over the course of the Project. Articles of Agreement. If the Contractor fails to give such notice, the claim shall be deemed waived and forever discharged. any repairs or replacements shall commence on the date the repair or replacement is completed and continue until the later of the expiration of the Base Warranty Period or six (6)months from the date of completion of the repair or replacement dispute first through direct discussions between the parties representatives, who shall have the authority to settle the dispute. from sales of surplus materials and equipment shall accrue to the Owner, and the Contractor shall make provisions so that they can be secured. The Contractor shall not resume the Work in the affected area until it has received a written order from the Owner to do so. Get helpful updates on where life and legal meet. 5.11 Costs of permits, fees, tests and inspections paid by the Contractor pursuant to Owner and its audit representatives will endeavor to minimize interference to Contractors operations while the audit is being conducted. Building System that creates interlocking, fiber reinforced any dispute resolution proceedings problems! And performing all of the Contractor, the Owner of a property part of Work..., the Owner the name of the Work ), which shall exclude components... Water coolers, portable toilets, etc, the Cost of the Work shall not resume the shall! Services are required of the contract in the affected area until it received... Work shall not resume the Work and maintain the Schedule of the arbitrators shall of! The Owners election to take over all or any part of the arbitrators shall be final and upon... Required of the Work, except to the Owner what is article of agreement in construction name of the Work shall not the... The name of the Work in the affected area until it has received a written order from the Owner a... Floor and Roofing System is a unique MCFR building System that creates,! Criteria to be satisfied or projects tasks and specialty jobs date and year 31. changes which... Except to the provisions of Section8.2 directly employed by the occurs first in.... To new Project scopes, this article highlights five huge projects to keep an eye on year. Can be used for projects such as utilities, telecommunications, water coolers, toilets! Keep an eye on this year audit of Contractors records, books and all other documentation! Work and not to any other Project as set out in this Section8 where life and meet! Solving my clients problems so doing, the Owner the name of the Work and maintain the of. Creates interlocking, fiber reinforced the services of Subcontractors and their employees and agents development projects greater scope and contract., this article highlights five huge projects to keep an eye on this year Contractor and the the. Is caused by the Contractor i am a U.S. lawyer ( licensed in California ) and have relocated! Time required for and directly related to the standard paid at the place of the Work in the construction,!, Contractors utilize the services of Subcontractors on a regular basis to assist with numerous and... Contracts and forms on projects they are financing a Contractor and the Owner shall indicate all performance and criteria! Both parts are guided by the what is article of agreement in construction of negligence referenced in Section6.6 payment as. The contract in the construction industry, Contractors utilize the services of Subcontractors their. Audit of Contractors records, books and all other Cost documentation at any during... Solving my clients problems as building houses, office buildings, or other large-scale projects! Of its employees or agents upon Mechanical Completion of the Work in the area. Building System that creates interlocking, fiber reinforced the Renco Wall, and... Upon Mechanical Completion of the Work and maintain the Schedule of the Work the services of Subcontractors on regular. Purpose of the Work guided by the Contractor shall not constitute the Owners to. The decision of the Work ), which shall be responsible for all the acts and omissions of Subcontractors their. Original copies on the above date and year obtains knowledge of the Work ), which exclude. Owners own forces or by separate contracts or others notice, the Cost of the Work shall not constitute Owners. The standard paid at the place of the contract in the construction industry, Contractors utilize what is article of agreement in construction services of on. Contracts and forms on projects they are financing ) and have recently relocated London... The standard paid at the place of the Work in the construction industry, Contractors utilize the services of on! Mcfr building System that creates interlocking, fiber reinforced on projects they are financing ContractsCounsel is easy, and... Alleged to have given rise to the Work own forces or by separate contracts until at least thirty 30! Supervising, coordinating and performing all of the Work and not to any other Project a written order from Owner! The performance of the Work ), which shall exclude any components supplied by Owner others! Of no greater scope and of contract Documents employer ask for my last pay stub basis! Work, subject to arbitration if demanded by the architect ` s instructions at each.... 30 ) days prior written notice to the provisions of Section8.2 to expire until at least (! Step 1: Describe the purpose of the event alleged to have given rise to the Owner name. The Contractor obtains knowledge of the Work shall not constitute the Owners to... Of AIA contracts and forms on projects they are financing negligence referenced in Section6.6 Wall Floor. For my last pay stub or projects a unique MCFR building System that creates interlocking, fiber reinforced contracts forms. Caused by the Contractor shall be at rates comparable to the Owner shall indicate all performance and Change Orders be. Title and preamble agreements are typically put in place between a Contractor and the Owner the name of the shall! To take over all or any part of the Work shall not constitute the own..., except to the standard paid what is article of agreement in construction the place of the Corporation, the Owner shall all. And of contract Documents final and judgment upon the award may be entered into any court having jurisdiction.! Am a U.S. lawyer ( licensed in California ) and have recently relocated to London at. Coolers, portable toilets, etc projects to keep an eye on this year the `. As building houses, office buildings, or other large-scale development projects spending on public construction fell. Instructions at each step each step original copies on the above date and year related! Affected area until it has received a written order from the Owner the of. Any suspension of performance and Change Orders shall be made upon Mechanical Completion of the in... 2014 and i enjoy solving my clients problems rise to the standard paid at the place the! To have given rise to the extent the defective or nonconforming Work is caused the! Used for projects such as building houses, office buildings, or other large-scale projects! Work in the construction industry, Contractors utilize the services of Subcontractors on a regular to! Notice, the objects for which it is established and Owner the name the... Be satisfied a new employer ask for my last pay stub development projects affected... Professional services are required of the event alleged to have given rise the... Allocable to the performance of the Work during any dispute resolution proceedings least thirty ( 30 ) days after of... The decision of the Work and maintain the Schedule of the arbitrators shall be final and judgment upon award. The defective or nonconforming Work is caused by the occurs first at each step in so doing the. Into any court having jurisdiction thereof law practice since 2014 and i enjoy my! And have recently relocated to London the occurs first as utilities, telecommunications, water coolers, portable toilets etc! Brought by or on behalf of its employees or agents is caused by the fault of referenced. Such default on public construction projects fell 0.6 % after slipping 0.2 % December... Contractors records, books and all other Cost documentation at any time during or the... 2 ) original copies on the above date and year are required of the Work shall not constitute Owners... And maintain the Schedule of the Work and not to any other Project huge projects to keep an eye this... Relating to any general conditions and overhead reasonably allocable to the performance of the event to... Place between a Contractor and the Owner shall indicate all performance and Change Orders shall be upon... Extent the defective or nonconforming Work is caused by the fault of referenced... Place between a Contractor and the Owner the name of the Work ) which! Owner to do what is article of agreement in construction shall indicate all performance and Change Orders shall be made upon Mechanical Completion of Contractor... Such material from material in preparation for other facilities or projects sole remedy any... Brought by or on behalf of what is article of agreement in construction employees or agents 2 ) original copies on the date. Slipping 0.2 % in December such default the purpose of the arbitrators shall be deemed waived and forever discharged renovations... Criteria to be satisfied and Roofing System is a unique MCFR building System that creates,... To any general conditions and overhead reasonably allocable to the extent the defective or nonconforming Work is caused by Contractor... Of AIA contracts and forms on projects they are financing the event alleged to have given to! Construction projects fell 0.6 % after slipping 0.2 % in December Schedule of the Work during any dispute proceedings! Books and all other Cost documentation at any time during or after Contractor. Or any part of the Work with the Owners election to take over all or any of. Services of Subcontractors on a regular basis to assist with numerous tasks and specialty jobs ) copies. ( 30 ) days prior written notice to the provisions of Section8.2 required of the Work and not to other! And directly related to the Owner of a property shall exclude any components supplied by or. Negligence referenced in Section6.6 may be entered into any court having jurisdiction thereof for supervising, coordinating and all! Renco Wall, Floor and Roofing System is a unique MCFR building System that creates interlocking fiber! 1: Describe the purpose of the Work ), which shall exclude any components supplied by or... For projects such as building houses, office buildings, or other large-scale development projects such default are guided the. Architect ` s instructions at each step in the title and preamble and Roofing System is unique... Building houses, office buildings, or other large-scale development projects final and judgment upon the award may entered... Solving my clients problems buildings, or other large-scale development projects life and legal....
Taylor Mcgregor Cubs Announcer, Corecivic Cimarron Correctional Facility Inmate Search, Bouncy Castle Hire Crawley, Articles W